Within the frame-work of the 2019 Public Investment Budget, the Contracting Authority (Mayor of Zhoa Council) hereby representing the State ofCameroon, launches an Open National Invitation to Tender under CONDITIONS OF EMERGENCY for the construction of a Pediatic Ward at the Integrated Health Centre Bafmen in Menchum Division. North West Region.

The works subject of this invitation to tender shall require the construction of a Pediatic Ward at the Integrated Health Centre Bafmen in Menchum Division, North West Region. The works required are found in the detail description mentioned in the respective bills of quantities and cost estimates.

The estimated cost of the operations (tasks) following feasibility studies stands as specified in the table below:-

The works subject of this invitation to tender shall be in one lot defined with specifications as in the table below:-

Participation in this invitation to tender is open to all registered and qualified companies or groups of companies based in the Republic of Cameroon with the required technical and professional expertise in the domain of construction accompanied by the necessary financial capability.

Works which form the subject of this invitation to tender shall be financed as per the programmed budget head of the 2019 Public Investment Budget (PIB 2019) of the Republic of Cameroon as specified in the table below:-

The Tender documents maybe consulted immediately after publication of this invitation to tender from the Contracting Authority during working hours  at the Zhoa Council.

TheTender documents shall be obtained immediately after publication of this invitation to tender from the Services ofthe Contracting Authority duringworking hours at the Zhoa Council.
The document shall be obtained upon presentation of a Public Treasury receipt showing the payment of a non-refundable sum of Sixty thousand (60,000) francs CFA.

Each bid written in English or French shall be signed bythe bidder orbya duly authorized Representative and presented in eight (8) copies thatisone (01) originalandseven (07) copies labelled as such. These shall be submitted in one sealed external envelope containing three (3) envelopes, that is. Envelope A: Administrative Documents. Envelope B: Technical documents and Envelope C: Financial . documents. It shall reach the Zhoa Council not later than the 28/03/2019 at 10 pm local time. The sealed external envelope shall be free ofall identification marks, failing which it shall be rejected.
The sealed external envelope addressed to the Contracting Authority shall bear the following inscriptions;

OPEN NATIONAL INVITATION TO TENDER
N° 0I_MINDDEVEL/ZC/ZCITB/20I9 OF THE 05/03/2019
FOR THE CONSTRUCTION OF APEDIATIC WARD AT THE INTEGRATED
HEALTH CENTRE IN BAFMEN, MENCHUM-DIVISION

(To be opened only during the bids opening session of the Tenders Board)

The maximum execution deadline provided for by the Project Owner for the execution of the works subject of this tender shall be ninety calendar days (three months) with effect from date of notification of the Service Order to start execution.

Each bidder shall enclose in his administrative documents a bid bond issued directly in the bidder's name by a first rate bank approved by the Ministry in charge of Finance and that shall respect the model in this tender file featuring on the list in document 12 of the tender file and valid for ninety (90) days beyond the originaldate of thevalidity of the offers.

Under risk of being rejected, administrative documents must be produced in originals or true copies certified by the issuing services of the required administrative documents (Examples: Taxation Officials, Bank Offiicials, etc.) or by Administrative Authorities as the case may be (Example: SDO, DO etc) and must imperatively be produced in accordance with the Special Tender Regulations. They must obligatorily not be older than three (03) months or must not be produced after the submission of the tender file. Double
certification shall not be accepted. Any bid that shall not be in conformity with the prescriptions of this notice and tender file shall be declared null and void, especially bids containing a bid bond not issued directly mthe bidder's name by afirst rate bank approved by the Ministry in charge of Finance.
The bid bond which shall only be released by the Contracting Authority shall be released for unsuccessful bidders not later than thirty (30) days after the period of bid validity. For the successful bidder to whom the contract will be awarded, the bid bond shall be returned to the contractor by the Contracting Authority once the final bond has been provided.
Bidders shall remain committed to their offers for a period ofninety (90) days from the last date for the submission of tenders, that is, the tenders shall be valid for 90 (ninety) days with effect from their submission deadline.
NB: The contractor shall, present the originals of the respective certified documents for strict verification of their authenticity during site installation.

Bids shall be opened by the Zhoa Council's Tenders Board in a single phase on the 28/03/2019 at 11pm local time in the hall at the Zhoa Council. Only bidders or their authorized representatives having aperfect knowledge of the file may attend the bid opening session. Note should be taken that in case of any ambiguities or differences during opening, only the original shall be considered authentic, that is. any bid which shall not comply with the requirements of the tender file shall be reiected.

Tender conformity shall be evaluated as per the following:

A) Eliminatory Criteria.

• Offers (bids) submitted after the deadline or time limit

• Bids submitted in unsealed external envelopesl

• External envelopes with identification marks or inscription

• Absence of a document in the administrative file -

• Administrative documents more than 3months old;

• Absence of original or properly certified administrative document or documents certified more than one time.

• False declaration or forged documents;
• Execution period longer than prescribed in theTender file
  
  • Technical evaluation mark less than 70% (respect ofthe essential criteria less of 70%):
  • Absence of quantified unit price in the financial bid.
  B) Essential Criteria They are primordial or key modalities in the judgment of the technical and financial capacity of candidates to execute the tasks forming the subject of the invitation to tender.
  They were determined in relation to the nature and content of the tasks to be executed. Hence in the evaluation of:-
  (i) Technical documents, it shall be the binary method (YES or NO) based on the following distribution of points:

• Absence of bid bond or bid bond not issued directly in bidder's name by a first rate bank approved by the Ministry incharge of Finance

NB:Bid bond for a group of enterprises must bear the name of mandated enterprise with the names of the other enterprises mentioned as well.

• Execution period longer than prescribed in theTender file
• Technical evaluation mark less than 70% (respect of the essential criteria less of 70%):

• Absence of quantified unit price in the financial bid.

B) Essential Criteria They are primordial orkey modalities in the judgment ofthe technical and financial capacity of candidates to execute the tasks forming the subject of the invitation to tender.
They were determined in relation to the nature and content of the tasks tobe executed. Hence in the evaluation of:-
(i) Technical documents, it shall be the binary method (YES or NO) based on the following distribution of points:

NB:
-Any Bid that shall not obtain 70% evaluation in the technical documents shall simply be rejected.
-Details of these main qualification criteria are specified in the evaluation grid found in the Special Tender Regulations (RPAO).
(ii) Financial Offer, it shall consist of going through the bill of quantities in reference to the unit price schedule and the subdetail of unit prices.

The contract shall be awarded to the lowest bidder who must have fulfilled the administrative technical and financial requirements.

Bidders shall remain committed to their offers for ninety (90) days from the deadline set for the submission of tenders (offers).

Additional information may be obtained during working hours from the Service forthe Contracts Award at the Council.

The Contracting Authority may at any time, amend this invitation to tender. Delays caused by such amendments shall also be considered in the period given to bidders to submit their bids.
The Contracting Authority may at any time, amend this invitation to tender. He shall publish the amendments and communicate same to companies that bought the tenders file. Delays caused by such amendments shall also be considered in the period given to bidders to submit their bids.