Within the frame-work ofthe PIP of 2019 Investment Budget, the Contracting Authority (The Mayor of Benakuma Council) for Menchum Valley Sub-Division, hereby representing the State ofCameroon, launches an Open National Invitation to tender under CONDITIONS URGENTL PROCEDURE for the construction of a block oftwo classrooms and head teacher office at Government School Kitundu Menchum Valley Sub-Division in Menchum Division -North West Region.

The works subject of this invitation to tender shall require construction of a block of two classrooms and head teacher office at Government School Kitundu Menchum Valley Sub-Division in Menchum Division -North West Region. The works and service required are found in the detail description mentioned in the respective bills of quantities and cost estimates

The estimated cost ofthe operations (tasks) following feasibility studies stands as specified in the table below

The works subject ofthis invitation to tender shall be in one lot defined with specifications as mthe table below:

Participation in this invitation to tender is open to all registered and qualified companies or groups of companies based in the Republic of Cameroon with the required technical and professional expertise in the domain ofconstruction accompanied by the necessary financial capability

Works which form the subject ofthis invitation to tender shall be financed as per the programmed budget head of the 2019 Common Decentralisation funds of the Republic of Cameroon as specified in the table below:

The Tender documents may be consulted immediately after publication of this invitation to tender from the Services of the Contracting Authority (Service in charge of the contracts award) during working hours at the Benakuma Council

The Tender documents shall be obtained immediately after publication of this invitation to tender from the Services of the Contracting Authority during working hours at the Benakuma Council. The document shall be obtained upon presentation ofa Public Treasury receipt showing the payment of an non refundable sum of Thirty five thousand (35,000) francs CFA.

Each bid written in English or French shall be signed by the bidder or by a duly authorized Representative and presented in seven (7) copies, that is one (01) original and seven (06) copies labelled as such. These shall be submitted in one sealed external envelope containing three (3) envelopes, that is, Envelope A: Administrative Documents, Envelope B; Technical documents and Envelqpe C: Financial documents. It shall reach the Benakuma Council (Above the Benakuma Market) not later than at 12am local time. The sealed external envelope shall be free ofall identification marks, failing which it shall be rejected. The sealed external envelope addressed to the Contracting Authority shall bear the following inscriptions:

OPEN NATIONAL INVITATION TO TENDER  

N° 004 ONIT/MINDDEVEL/BC/BITB/MAYOR /DD/MCH/2019 FOR THE CONSTRUCTION OF A BLOCK OF TWO CLASSROOMS AND HEAD TEACHERS OFFICE AT GOVERNMNET SCHOOL KITUDU ,MENCHUM VALLEY SUB-DIVISION, MENCHUM DIVISION IN THE NORTH-WEST REGION
(To be opened only during the bids opening session of the Tenders Board)

The maximum execution deadline provided for by the Project Owner for the execution ofthe works subject ofthis tender shall be ninety calendar days (three months) with effect from date ofnotification of the Service Order to start execution

Each bidder shall enclose in his administrative documents a bid bond issued directly in the bidder's name by a first rate bank approved by the Ministry in charge of Finance and that shall respect the model in this tender file featuring on the list in document 12 of the tender file and valid for ninety (90) days beyond the original date of the validity of the offers.

Under risk of being rejected, administrative documents must be produced in originals or true copies certified by the issuing services of the required administrative documents (Examples: Taxation Officials, Bank Officials, etc.) or by Administrative Authorities as the case may be (Example: SDO, DO etc) and must imperatively be produced in accordance with the Special Tender Regulations. They must obligatorily not be older than three (03) months or must not be produced after the submission of the tender file. Double certification shall not be accepted. Any bid that shall not be in conformity with the prescriptions ofthis notice and tender file shall be declared null and void, especially bids containing a bid bond not issued directly in the bidder's name by afirst rate bank approved by the Ministry in charge of Finance. The bid bond which shall only be released by the Contracting Authority shall be released for unsuccessml bidders not later than thirty (30) days after the period ofbid validity. For the successful bidder to whom the contract will be awarded, the bid bond shall be returned to the contractor by the Contracting Authority once the final bond has been provided. Bidders shall remain committed to their offers for aperiod of ninety (90) days from the last date for the submission of tenders, that is, the tenders shall be valid for 90 (ninety) days with effect from their submission deadline.

NB: The contractor shall, present the originals ofthe respective certified documents for strict verification of their authenticity during site installation.

Bids shall Ibe opened by the Benakuma Council Internal Tenders Board in a single phase on the 24 APR 2019 at 1pm local time in the hall at the Benakuma Council, Menchum. Only bidders or their ''authorized representatives having a perfect knowledge ofthe file may attend the bid opening session. Note should be taken that in case of any ambiguities or differences during opening, only the original shall be considered authentic, that is, any bid which shall not comply requirements of the tender file shall be rejected.

EVALUATION CRITERIA:

Tender conformity shall be evaluated as per the following:
A) Eliminatory Criteria.

- Offers (bids) submitted after the deadline or time limit;

- Bids submitted in unsealed external envelopes.

- External envelopes with identification marks or inscriptions,

- False declaration or forged documents ;

- Absence of bid bond

NB: Bid bond for a group of enterprises must bear the name ofmandated enterprise with the names of the other enterprises mentioned as well.

- Execution period longer than prescribed in the Tender file

- Technical evaluation mark less than 75% (non-respect of 75% of the essential criteria);

- Absence of quantified unit price (omission of a unit price in the financial bid).
B) Essential Criteria They are primordial or key modalities in the judgment of the technical and financial capacity of candidates to execute the tasks forming the subject of the invitation to tender. They were determined in relation to the nature and content ofthe tasks to be executed. Hence in the evaluation of:

(i) Technical documents, it shall be the binary method (YES or NO) based on the following distribution of points:

 NB: -

Any Bid that shall not obtain 75% evaluation in the technical documents shall simply be rejected.

-Details of these main qualification criteria are specified in the evaluation grid found in the Special Tender Regulations (RPAO).

(ii) Financial Offer, it shall consist of going through the bill of quantities in reference to the unit price schedule and the sub detail of unit prices.

The eontract shall be awarded to the lowest bidder who must have fulfilled the administrative, technical and financial requirements

Bidders shall remain committed to their offers for ninety (90) days from the deadline set tor the submission oftenders (offers).

Additional information may be obtained during working hours from the Service for the Contracts Award at the Benakuma Council, Menchum Valley SubDivision.

The Contracting Authority may at any time, amend this invitation to tender. Delays caused by such amendments shall also be considered in the period given to bidders to submit their bids.

The Contracting Authority may at any time, amend this invitation to tender. He shall publish the amendments and communicate same to companies that bought the tenders file. Delays caused by such amendments shall also be considered in the period given to bidders to submit their bids.