Within the frame-work of the 2020 Public Investment Budget, the Contracting Authority (Mayro of Banakuma Council). hereb\ representing the State of Cameroon, launches an Open National Invitation to Tender under CONDITIONS OF EMERGENCY for the construction ofa block of two classrooms at Government School Badu in Menchum Valley Sub Division, Mcnchum Division -North West Region.

The works subject of this invitation to tender shall require the construction of a block of two classrooms in Government School Badu in Menchum Valley Division Menchum Division -North West Region. The works required are found in the detail description mentioned in the bills of quantities and cost estimates.

The estimated cost of the operations (tasks) following feasibility studies stands as specified in the table below.

The works subject of this invitation to tender shall be defined with specifications as mthe table below.-

Participation in this invitation to tender is open to all registered and qualified companies or groups of companies based in the Republic of Cameroon with the required technical and professional expertise in the domain of construction accompanied by the necessary financial capability.

Works which form the subject of this invitation to tender shall be financed as per the programmed budget head of the 2020 Public Investment Budget (PIB 2020) of the Republic of Cameroon as specified in the table below:-

The works subject of this invitation to tender shall require the construction of a block of two classrooms in Government School Badu in Menchum Valley Division Menchum Division -North West Region. The works required are found in the detail description mentioned in the bills of quantities and cost estimates.

The Tender doeuincrits shall be obtained Immediately after publication of this invitation to tender from the Services of the Contracting Authority during working hours at the Benakuma Council. The document shall be obtained upon presentation of a Public Treasury receipt/Municipal Treasury showing the payment ofanon-refundable sum of Thirty eight thousand (38,000) francs CFA.

Each bid written in English or French shall be signed by the bidder or by a duly authorized Representative and presented in seven (7) copies,that is one (01) original and six (06) copies labelled as such. These shall be submitted in one sealed external envelope containing three (3) envelopes, that is, Envelope A: Administrative Documents, Envelope B: Technical documents an Envelope C: Financial documents It shall reach the Benakuma Council (at the Benakuma) not later than 25/02/2020 AT 12:00 local time. The sealed external envelope shall be free of all identification marks, failing which it shall be rejected

Ihe sealed external envelope addressed to the ConiraeLing Authority shall bear llie following inscriptions:

OPEN NATIONAL INVITATION TO TENDER

N° 001/ONIT/M1NDEVEL/BC/MAYOR/BCITB/MCH/2020 of 04 FEV 2020 CONSTRUCTION OFABLOCK OF TWO CLASSROOMS AT GOVERNMENT SCHOOLS BADU, MENCHUM VALLEY SUB DIVISION IN MENCHUM DIVISION

The maaximum execution deadline provided for by the Project Owner for the execution of the works subject of this tender shall be ninety calendar days (three months) with effect from date of notification of the Service Order to start execution.

Each bidder shall enclose in his administrative documents a bid bond issued directly in the bidder's name by a first rate bank approved by the Ministry in charge of Finance and that shall respect the model in this lender file featuring on the list in document 12 of the tender file and valid for ninety (90) days beyond the original date of the validity of the offers.

Under risk of being rejected, administrative documents must be produced in originals or true copies certified by the issuing services of the required administrative documents (Examples: Taxation Oficiais, Bank Officials, etc.) or by Administrative Authorities as the case may be (Example: SDO, DO etc) and must imperatively be produced in accordance with the Special Tender Regulations. They must obligatorily not be older than three (03) months or must not be proddled after the submission of the tender file. Double certification shall not be accepted. Any bid that shall not be in conformity with the prescriptions of this notice and tender file shall be declared null and void, especially bids containing a bid bond not issued directly in the bidder's name by a first rate bank approved by the Ministry in charge of Finance.
The bid bond which shall only be released by the Contracting Authority shall be released for unsuccessful bidders not later than thirty (30) days after the period of bid validity. For the successful bidder to whom thet contract will be awarded, the bid bond shall be returned to the contractor by the Contracting Authority once the final bond has been provided.
Bidders shall remain committed to their offers for a period of ninety (90) days from the last date for the submission of tenders, that is, the tenders shall be valid for 90 (ninety) days with effect from their submission deadline.
NB: The contractor shall, present the originals of the respective certified documents for strict verification of their authenticity during site installation.

Bids shall be opened by the Benakuma council Internal council Tenders Board in asingle phase for ail in that order on the 25 Fev 2020 pm at 1PM local time in the hall at the Benakuma Council. Only bidders or their authorized representatives having a perfect knowledge of the file may attend the bid opening session. Note should be taken that in case of any ambiguities or differences during opening, only the original shall be considered authentic, that is, any bid which shall not comply with the requirements of the tender file shall be rejected.

EVALUATION CRITERIA:
Tender conformity shall be evaluated as per the following:
A) Eliminatory Criteria.
- Offers (bids) submitted after the deadline or time limit;
- Bids submitted in unsealed external envelopes.
- External envelopes with identification marks or inscriptions,
-False declaration orforged documents ;
-Absence of bid bond or bid bond not issued directly in bidder's name by a first rate bank approved by the Ministry in charge of Finance
NB: Bid bond for a group ofenterprises must hear the name of mandated enterprise with the names of the other enterprises mentioned aswell.

Execution period longer than prescribed in the lender fiie
Technical evaluation mark less than 75% (respect oj the essential criteria less of 75%);
Absence or quantified unit price in file financial bid.
B) Essetial Criteria They are primordial or key modalities in the judgment of the technical and financial capacitv of candidates to execute the tasks ibrming the subject of the invitation to tender.
They were determined in relation lo the nature and content of the tasks to be executed. Hence in the evaluation of:-
(i) Technical documents, it shall be the binary method (YES or NO) based on the following distribution of points:

NB:
-Any Bid that shall not obtain 75% evaluation in the technical documents shall simply be rejected.
-Details of the se main qualification criteria are specified in the evaluation grid found in the Special Tender Regulations(RPAO).
(ii) Financial Offer, it shall consist of going through the bill ofquantities in reference to the unit price schedule and the sub detail of unit prices.

The contract shall be awarded to the lowest bidder who must have fulfilled the administrative, technical and financial requirements.

Bidders shall remain committed to their offers for ninety (90) days from the deadline settor the submission of tenders (offers).

Additional information may be obtained during working hours from the Service for the Contracts Award at the Benakuma Council.

Amendment to the invitation to TENDER:
The Contracting Authority may at any time, amend this invitation to tender. He shall publish the amendments and communicate same to companies that bought the tenders file. Delays caused by such amendmenLs shall also be considered in the period given to bidders to submit their bids.