Within the frame-work of the 2020 Public Investment Budget, the Contracting Authority (THE MAYOR OF MISAJE COUNCIL), hereby representing the State of Cameroon, launches under an emereencv procedure an Open National Invitation to tender FOR THE CONSTRUCTION OF AMARKE THANGAR WH1I 16 SALES SLAB AT BANSOBI MARKET IN MISAJE COUNCIL AREA, DONGA MANTUNG DIVISION - North West Region.

The works subject of this invitation to tender shall require THE CONSTRUCTION OF A MARKET HANGAR WITH 16 SALES SLAB AT BANSOBI MARKET -North West Region. The works and service required are found in the detail description mentioned in the respective bills ofquantities and cost estimates.

 Estimated Cost 12 500 000 FCFA

The works subject ofthis invitation to tender shall be in one lot defined with specifications as in the table below:- 

Participation in this invitation to tender is open to all registered and qualified companies or groups of companies based in the Republic of Cameroon with the required technical and professional expertise in the domain of construction accompanied by thenecessary financial capability

Works which form the subject of this invitation to tender shall be financed as per the programmed budget head of the 2020 Public Investment Budget (PIB 2020- MINDDEVEL) of the Republic of Cameroon as specified in the table below:-

The Tender documents may be consulted immediately after publication of this invitation to tender from the Services of the Contracting Authority (Service in charge of the contracts award) during working hours at the MISAJE council premises.
 

The Tender documents shall be obtained immediately after publication ofthis invitation to tender Services of the Contractine Authority during working hours at the MISAJE Council office. The document shall be obtained upon presentation of a Treasury receipt showing the payment of a non-refundable sum of twenty five thousand (25 000) francs CFA from MISAJE council treasury

Each bid written in English or French shall be signed by the bidder or by a duly authorized Representative and presented in seven (7) copiese and that ise one (01) original and six (06) copies labelled as such. These shall be submitted Envelope RB. Technical r documents containing and Envelope three (3) C:envelopes, Financial that documents. is. Envelope It shall A:reach Administrative the MISAJEDocuments council in the service in charge of contract award not later than 8th May 2020 At 10am local time The sealed external envelope shall be free of all identification marks, failing which it shall be rejected.
The sealed external envelope addressed to the Contracting Authority shall bear the following inscriptions:

OPEN NATIONAL INVITATION TO TENDER
PROCEDURE FOR THE CONSTRUCTION OF AMARKET HANGAR launched WITHunder 16 SALES emergency SLAB AT
BANSOBI MARKET IN MISAJE COUNCIL AREA, DONGA MANTUNG DIVISION

(To be opened only during the bids opening session of the Tenders Board)

T'he maximum execution duration provided for by the Project Owner for the execution of the works subiect of this tender shall be 90 calendar days THREE (3 months) with effect from date of notification of the Service Order to start execution.

Each bidder shall enclose in his administrative documents abid bond issued directly in the bidder's name by a first rate bank approved by the Ministry in charge of Finance and that shall respect the model in this tender file featurmg on the list in document 12 of the tender file and valid for ninety (90) days beyond the origmal date of the validity ot the offers. 

Under risk of being rejected, administrative documents must be produced in originals or true copies certified by the issuing services of the required administrative documents (Examples: Taxation Officials, Bank Officials, etc.) or by Administrative Authorities as the case may be (Example: SDO, DOetc) and must imperatively be produced in accordance with the Special Tender Regulations. They must obligatorily not be older than three (03) months or must not be produced after the submission of the tender file. Double
certification shall not be accepted. Any bid thai shall not be in conformity with the prescriptions of this notice and tender file shall be declared null and void, especially bids containing a bid bond not issued directly in the bidder's name by a first rate bank approved by the Ministry in charge of Finance.
The bid bond which shall only be released by the Contracting Authority shall be released for unsuccessful bidders not later than thirty (30) days after the period of bid validity. Forthe successful bidder to whom the contract will be awarded, the bid bond shall be returned to the contractor by the Contracting Authority once the final bond has been provided.
Bidders shall remain committed to their offers for a period of ninety (90) days from the last date for the submission of tenders, that is, the tenders shall be valid for 90 (ninety) days with effect from their submission deadline.
NB: The contractor shall, present the originals of the respective certified documents for strict verification of their authenticity during site installation.

Bids shall be opened by the MISAJE council Tenders Board in a single phase on the 8th May 2020 at 11:00 am local time in the conference hail of the MISAJE council premises. Only bidders or their  authorized representatives having aperfect knowledge of the file may attend the bid opening session. Note should be taken that in case of any ambiguities or differences during opening, only the original shall be considered authentic, that is, any bid which shall not comply with the requirements of the tender file shall be
rejected.
 

  Tender conformity shall beevaluated as perthe following:
A) Eliminatory Criteria.
• Offers (bids) submitted after the deadline or time limit;
- Bids submitted in unsealed external envelopes.
- External envelopes with identification marks or inscriptions.
- Absences of a document in the administrative file and not submitted within 48hours upon request.
- Administrative documents more than 3months old;
- False declaration or forged documents ;
- Absence of bid bond or bid bond not issued directly in bidder's name by a first rate bank approved
by the Ministry in charge of Finance
NB: Bid bond for a group of enterprises must bear the name of mandated enterprise with the
names ofthe other enterprises mentioned as well
• Execution period longer than prescribed in the Tender file
- Technical evaluation mark less than 80% (non-respect of 80% of the essential criteria):
Absence of" quantified unit price fomi.ssiori ofa unitprice in thefinancial bid).
B) Essential Criteria Theyare primordial or key modalities in thejudgment of the technical and financial capacity of candidates to execute the tasks forming the subject of the invitation to tender.
They were determined in relation to the nature and content of the tasks to be executed. Hence int he evaluation of:-
(i) Technical documents, it shall be the binary method (YES or NO) based on the following distribution of points:

NB:
-Any Bid that shall not obtain 80% evaluation in the technical documents shall simply be rejected.
-Details of these main qualification criteria are specified in the evaluation grid found in the Special Tender Regulations (RPAO).
(ii) Financial Offer, it shall consist of going through the bill of quantities in reference to the unit price schedule and the sub detail of unit prices.

Under risk of being rejected, administrative documents must be produced in originals or true copies certified by the issuing services of the required 

The contract shall be awarded to the lowest bidder who must have fulfilled the administrative, technical and financial requirements.

Bidders shall remain committed to their offers for ninety (90) days from the deadline set for the submission of tenders (offers).

Additional inrormation may be obtained during working hours from the Service for the Contracts Award at IMISAJE
council.
 AMENDMENT TO THE INVITATION TO TENDER:
The Contracting Authority may at any time, amend this invitation to tender. Delays caused by such amendments
shall also be considered in the periodgiven to bidders to submittheir bids.
The Contracting Authority may at any time, amend this invitation to tender. He shall publish the amendments and communicate same to companies that bought the tenders file. Delays caused by such amendments shall also be considered in the period given to bidders to submit their bids