Within the framework of the 2020 Public Investment Budget, the Contracting Authority (THE MAYOR OF NDU COUNCIL), hereby representing the State of Cameroon, launches an Open National Invitation to tender by emergency procedure for the Construction of A DISTRICT MEDICAL CENTRE (D.M.C) MBAKOP in Ndu Subdivision, Donga Mantung Division North West Region

The works subject of this invitation to tender shall require the Construction of the DISTRICT MEDICAL CENTRE (D.M.C) MBAKOP in Ndu Subdivision, Donga Mantung Division North West Region. The works and service required are found in the detail description mentioned in the respective bills of quantities and cost estimates.

The estimated cost of the operations (tasks) following feasibility studies stands for seventy million (70,000,000) CFAF.

The works subject of this invitation to tender shall be in one lot :  Construction of the DISTRICT MEDICAL CENTRE (D.M.C) MBAKOP in NDU Sub Division, DONGA MANTUNG Division, North West Region.

Participation in this invitation to tender is open to all registered and qualified companies or groups of companies based in the Republic of Cameroon with the required technical and professional expertise in the domain of construction accompanied by the necessary financial capability.

Works which form the subject of this invitation to tender shall be financed as per the programmed budget head of the 2020 Public Investment Budget (PIB 2020- MINSANTE) of the Republic of Cameroon; vote of charge authorization: 54 40531 07 641640 2272 611

The Tender documents may be consulted immediately after publication of this invitation to tender from the Services of the Contracting Authority (Service in charge of the contracts award) during working hours at the NDU council premises.

The Tender documents shall be obtained immediately after publication of this invitation to tender from the Services of the Contracting Authority during working hours at the Ndu Council office. The document shall be obtained upon presentation of a Treasury receipt showing the payment of a non-refundable sum of one hundred thousand (100 000) francs CFA from NDU council treasury.

Each bid written in English or French shall be signed by the bidder or by a duly authorized Representative and presented in eight (8) copies that is one (01) original and seven (07) copies labelled as such. These shall be submitted in one sealed external envelope containing three (3) envelopes, that is, Envelope A: Administrative Documents, Envelope B: Technical documents and Envelope C:Fmancial documents. It shall reach the NDU council in the service in charge of contract award not later than 11 MAY 2020 local time. The sealed external envelope shall be free of all identification marks, failing which it shall be rejected.

The sealed external envelope addressed to the Contracting Authority shall bear the following inscriptions:

 OPEN NATIONAL INVITATION TO TENDER BY EMERGENCY PROCEDURE  N° 03 /ONIT/MINDDEVEL/NWR/DMD/NC/NCITB/2020 OF 16 APR 2020 FOR THE CONSTRUCTION WORKS OF THE DISTRICT MEDICAL CENTRE (D.M.C) MBAKOP IN NDU SUBDIVISION, DONGA MANTUNG DIVISION NORTH WEST REGION

(To be opened only during the bids opening session of the Tenders Board)

The maximum duration of execution provided for by the Project Owner for the execution of the works subject of this tender shall be 120 calendar days (4 months) with effect from date of notification of the Service Order to start execution.

Each bidder shall enclose in his administrative documents a bid bond  of one million and four hundred thousand (1,400,000) CFAF issued directly in the bidder's name by a first rate bank approved by the Ministry in charge of Finance and that shall respect the model in this tender file featuring on the list in document 12 of the tender file and valid for ninety (90) days beyond the original date of the validity of the offers.

Under risk of being rejected, administrative documents must be produced in originals or true copies certified by the issuing services of the required administrative documents (Examples: Taxation Officials, Bank Officials, etc.) or by Administrative Authorities as the case may be (Example: SDO, DO etc) and must imperatively be produced in accordance with the Special Tender Regulations. They must obligatorily not be older than three (03) months or must not be produced after the submission of the tender file. Double certification shall not be accepted. Any bid that shall not be in conformity with the prescriptions of this notice and tender file shall be declared null and void, especially bids containing a bid bond not issued directly in the bidder's name by a first rate bank approved by the Ministry in charge of Finance. The bid bond which shall only be released by the Contracting Authority shall be released for unsuccessful bidders not later than thirty (30) days after the period of bid validity. For the successful bidder to whom the contract will be awarded, the bid bond shall be returned to the contractor by the Contracting Authority once the final bond has been provided.

Bidders shall remain committed to their offers for a period of ninety (90) days from the last date for the submission of tenders, that is, the tenders shall be valid for 90 (ninety) days with effect from their submission deadline.

NB: The contractor shall, present the originals of the respective certified documents for strict verification of their authenticity during site installation.

Bids shall be opened by the NDU council Tenders Board in a single phase on the  11 MAY 2020 at 11 am local time in the conference hall of the NDU council premises. Only bidders or their authorized representatives having a perfect knowledge of the file may attend the bid opening session. Note should be taken that in case of any ambiguities or differences during opening, only the original shall be considered authentic, that is, any bid which shall not comply with the requirements of the tender file shall be rejected.

Tender conformity shall be evaluated as per the following:

A) Eliminatory Criteria.

- Offers (bids) submitted after the deadline or time limi;

 - Bids submitted in unsealed external envelopes;

 - External envelopes with identification marks or inscriptions;

  -  Absence of a document in the administrative file;

   -  Administrative documents more than 3 months old;

   -Bidders suspended from public procurement.

  -  False declaration or forged documents;

  -Absence of an acceptable bid bond;

NB:  Bid bond for a group of enterprises must bear the name of mandated enterprise with the names of the other enterprises mentioned as well.

 - Execution period longer than prescribed in the Tender file four months;

  - Technical evaluation mark less than 80% (non-respect of 80% of the essential criteria);

  - Absence of quantified unit price (omission of a unit price in the financial bid).

B) Essential Criteria

They are primordial or key modalities in the judgment of the technical and financial capacity of candidates to execute the tasks forming the subject of the invitation to tender. They were determined in relation to the nature and content of the tasks to be executed. Hence in the evaluation of:

- (i) Technical documents, it shall be the binary method (YES or NO) based on the following distribution of points:

NB:

 -Any Bid that shall not obtain 80% evaluation in the technical documents shall simply be rejected.

 -Details of these main qualification criteria are specified in the evaluation grid found in the Special Tender Regulations (RPAO).

- (ii) Financial Offer, it shall consist of going through the bill of quantities in reference to the unit price schedule and the sub detail of unit prices.

The contract shall be awarded to the lowest bidder who must have fulfilled the administrative, technical and financial requirements.

Bidders shall remain committed to their offers for ninety (90) days from the deadline set for the submission of bids

Additional information may be obtained during working hours from the Service for the Contracts Award at NDU council.

NB: The Contracting Authority may at any time, amend this invitation to tender. Delays caused by such amendments shall also be considered in the period given to bidders to submit their bids. The Contracting Authority may at any time, amend this invitation to tender. He shall publish the amendments and communicate same to companies that bought the tenders file. Delays caused by such amendments shall also be considered in the period given to bidders to submit their bids.