Within the Framework of the 2024 Public Investment Budget, the Contracting Authority (The Mayor of Furu Awa Council), hereby representing the State of Cameroon, launches an Open National Invitation to tender by EMERGENCY PROCEDURE   FOR THE ESTABLISHMENT OF A FISH POND IN FURU AW TOWN, IN FURU AWA SUB DIVISION MENCHUM DIVISION, NORTH WEST REGION

The works subject of this invitation to tender shall require for the Establishment of a fish pond in Furu awa town, Furu awa sub Division Menchum Division, north west region. The works and service required are found in the detail description mentioned in the respective bills of quantities and cost estimates.

The estimated cost of the operations (tasks) following feasibility studies stands as specified in the table below:-

The works subject of this invitation to tender shall be in one lot defined with specifications as in the table below:-

Participation in this invitation to tender is open to all registered and qualified companies or groups of companies based in the Republic of Cameroon with the required technical and professional expertise in the domainof construction accompanied by the necessary financial capability.

Works which form the subject of this invitation to tender shall be financed as per the program budget head of the 2024 Public Investment Budget (PIB 2024) of the Republic of Cameroon as specified in the table below:-

The Tender documents may be consulted immediately after publication of this invitation to tender from the Services of the Contracting Authority (Furu awa Council office) during working hours.

The Tender documents shall be obtained immediately after publication of this invitation to tender from the Service of the Contracting Authority during working hours at the Furu awa Council office. The document shall be obtained upon presentation of a Public Treasury receipt showing the payment of a non-refundable sum of sixty thousand (60,000) francs CFA.

Each offer or bid drafted in English or French in seven (07) copies including the original and six (06) copies marked as such in accordance with the prescription of the tender file should be submitted against a receipt at Furu awa council Menchum Division not later than 31/01/2024 at 10.00pm local time and should carry the inscription:

The maximum execution deadline provided for by the Project Owner for the execution of the works subject of this tender shall be ninety (90) calendar days (three months) with effect from date of notification of the Service Order to start execution

Each bidder shall enclose in his administrative documents a bid bond, or Certified cheque, Bank cheque, Legal mortgage or Bank Guarantee issued directly in the bidder’s name by a first rate bank approved by the Ministry in charge of Finance and that shall respect the model in this tender file featuring on the list in document 12 of the tender file and valid for ninety (90) days beyond the original date of the validity of the offers.

Under risk of being rejected, administrative documents must be produced in originals or true copies certified by the issuing services of the required administrative documents (Examples: Taxation Officials, Bank Officials, etc.) or by Administrative Authorities as the case may be (Example: SDO, DO etc) and must imperatively be produced in accordance with the Special Tender Regulations. They must obligatorily not be older than three (03) months or must not be produced after the submission of the tender file. Double certification shall not be accepted. Any bid that shall not be in conformity with the prescriptions of this notice and tender file shall be declared null and void, especially bids containing a bid bond not issued directly in the bidder’s name by a first rate bank approved by the Ministry in charge of Finance.

      The bid bond which shall only be released by the Contracting Authority shall be released for unsuccessful bidders not later than thirty (30) days after the period of bid validity. For the successful bidder to whom the contract will be awarded, the bid bond shall be returned to the contractor by the Contracting Authority once the final bond has been provided.

    Bidders shall remain committed to their offers for a period of ninety (90) calendar days from the last date for the submission of tenders, that is, the tenders shall be valid for ninety (90) calendar days with effect from their submission deadline.

NB: The contractor shall, present the originals of the respective certified documents for strict verification of their authenticity during site installation.

The opening of bids in one phase shall be done on the 31/01/2024 at 11:00 am in the conference hall of Furu awa council by the competent Tenders Board. Only bidders may attend or be duly represented by a person of their choice, who has full knowledge of the file and mandated in that capacity.

EVALUATION CRITERIA:

Tender conformity shall be evaluated as per the following:

-          Offers (bids)  submitted after the deadline or time limit shall be rejected;

-          Bids submitted in unsealed external envelopes shall be rejected.

-          External envelopes with identification marks or inscriptions which may lead to the identification of the said company shall be rejected.

-          Absence of original or properly certified administrative document or documents certified more than one time shall be given 48 hours to replace it.

-          False declaration or forged documents shall be given 48 hours to replace them;

-          Absence of bid bond, or Certified cheque, Bank cheque, Legal mortgage or Bank Guarantee or bid bond not issued directly in bidder’s name by a first rate bank approved by the Ministry in charge of Finance the bidder shall simply be rejected.

           NB: Bid bond or any bid security for a group of enterprises must bear the name of mandated enterprise with the names of the other enterprises mentioned as well.

A)             Essential Criteria They are primordial or key modalities in the judgment of the technical and financial capacity of candidates to execute the tasks forming the subject of the invitation to tender. They were determined in relation to the nature and content of the tasks to be executed. Hence in the evaluation of:-

(i)                 Technical documents, it shall be the binary method (YES or NO) based on the following distribution of points :

   NB:

       -Any Bid that shall not obtain 75 % evaluation in the technical documents shall simply be rejected.

             -Details of these main qualification criteria are specified in the evaluation grid found in the Special Tender Regulations (RPAO).

(ii) Financial Offer, it shall consist of going through the bill of quantities in reference to the unit price schedule and the sub detail of unit prices.

The contract shall be awarded to the lowest bidder who must have fulfilled the administrative, technical and financial requirements.

Bidders shall remain committed to their offers for ninety (90) calendar days from the deadline set for the submission of tenders (offers).

COMPLEMENTARY INFORMATION:

   Additional information may be obtained during working hours from the Service of Furu awa Council.

AMENDMENT TO THE INVITATION TO TENDER:

     The Contracting Authority may at any time, amend this invitation to tender. Delays caused by such amendments shall also be considered in the period given to bidders to submit their bids.

      He shall publish the amendments and communicate same to companies that bought the tenders file.

.